Terms & Conditions

If you have any queries please get in touch with Sharyn on 0425 753 803

1. ACCEPTANCE
1.1 These Terms and Conditions (Terms) are between Sharyn Schultz trading as Melbourne Dyeing (ABN:45176479425 ), its successors and assignees (referred to as “we”, “us” or “our”) and the Client described in the Quote (referred to as “customer” “you” or “your”), and collectively the Parties.

1.2 You have requested the Services and Goods set out in your Quote (Services).
You accept the Quote and these Terms by:
a) confirming by email/text message that you accept the Quote.
b) instructing us to proceed with the Services, or
c) paying the deposit as set out in the Quote.
1.3 Our agreement with the Customer is comprised of the following documents which contain the entire understanding between the parties:
a) These Terms & Conditions
b) Quote

1.4 You agree that these Terms form the agreement under which we will supply Services and Goods to you. Please read these Terms & Conditions carefully. Please get in touch with us if you have any questions. Purchasing Services and Products from us indicates that you have had sufficient opportunity to read these Terms & Conditions and contact us if needed, that you have read, and accepted. It will comply with these Terms & Conditions, and that you are 18 years or older, or have the consent of a legal guardian who is 18 years or older. You must not order services from us if you are under 18 years of age or do not have the consent of a legal guardian who is 18 years or older. If you do not agree to these Terms & Conditions, you should not purchase from us.

2. SERVICES & SUPPLY OF GOODS
2.1 We agree to perform the services with due care and skill and supply the goods to the customer at the time as detailed in your Quote.

2.2 All Goods are subject to availability, and we reserve the right to substitute products provided that the quality is equal to or better than the one specified.

2.3 The client acknowledges that finished supplied goods or services may on occasion exhibit variations in shade, colour, texture, surface and finish although we do aim for 90-95%.

2.4 We may provide the Services or installation of Goods to you using our employees and/or contractors, and they are included in these Terms.

2.5 Third parties who are not our employees or our direct contractors (Third Parties) will be your responsibility. We are not responsible for the services provided by Third Parties. I.e., Airtasker or Removalist services.

2.6 If you request amended, varied or additional services, including but not limited to changes in services (Additional Services), we have discretion as to whether we perform this work and whether an adjustment to the Fee may be required in respect of the same. If we are unable to accommodate the Additional Services, we may request that we be paid for Services performed to date and terminate these Terms.

3. PRICE, INVOICING AND PAYMENT
3.1 The total amount payable and method of payment by you to us is detailed in your quotation.

3.2 You agree to pay us a deposit as reflected in your quote. The deposit is due upon your acceptance of the Quote and within 7 days.

3.3 A maximum of 10% deposit will be applicable for work greater than $20,000.00 AUD as required by law.

3.4 The business may submit a payment claim or progress payments at intervals not less than one (1) month for work performed up to the end of each month.

3.5 If progress payments are requested, a 40% deposit is required for materials.

3.6 The final amount payable must be finalised on completion of the work.
All amounts payable and due are accepted by direct deposit/ eftpos on completion. you will receive an emailed remittance at the point in time when the funds have cleared.

3.7 We reserve the right to charge late fees and interest on any overdue payment. Interest shall accrue at the rate prescribed by the Penalty Interest Rates Act 1983 (Vic) from the due date of payment until the date of full payment.

3.8 We reserve the right to cease work if payments or progress payments are not made, or for any other reason at our sole discretion.

3.9 This contract makes no provision for any works on-site with identifying any material containing asbestos.

3.10 Price variations may occur during work being completed in the event of, but not limited to, excessive greases, fake leather, and chemical reactions. Or an unidentified issue not notified to us.

3.11 Price variations may occur in the event of an unknown history of the job.

3.12 Should we engage debt recovery/collectors you will be liable for all costs associated including legal fees.

4. DELIVERY AND INSTALLATION
4.1 We may conduct a site inspection of the Premises on or before the day work is to be completed to confirm site access, OHS standards, electricity connection and for any other reason necessary to perform the work.

4.2 By accepting the Quote and these Terms, you grant permission for us to enter the Premises at any reasonable time as pre-arranged for the return or services to be completed.

4.3 You authorise us (including our contractors) to deliver (not install) your returned goods in your Quote.

4.4 You warrant that you are the Owner or have appropriate authorised consent from the Owner of the Property Address.

4.5 The client acknowledges that we are not furniture removalists although we take all care when moving furniture. We will not carry furniture downstairs; A time will be given closer to the day.
Please note that although we do take care with moving the items around we are not furniture Removalists.
We do have two men from air tasker, that can meet onsite to help with moving furniture, to and from my van.
They generally charge $100 each way.
You will pay them directly.
If you require this then please let me know
For the easiest and quickest pick up and delivery all we need is full driveway access.
If the item is in the house, then it will need to be taken outside and put in the garage or somewhere if possible, that way we can then easily carry it to the van/trailer.
If you live in an apartment, we will require lift access and car park access.
If u require a certain colour, then you will have to provide a colour swatch of some kind on arrival for pickup.

4.6 The client acknowledges and accepts your date of commencement of the workday be subject to change and work may be delayed for reasons of inclement weather or conditions, lack of manpower availability, any order of a court or tribunal that the work be suspended, any industrial dispute, a variation to the work, any unavailability of materials, any other matter beyond the businesses control. The client will be notified in writing of any delays.

5. PERMITS AND INSPECTIONS (corporate and/or building sites )
5.1 You agree to complete and execute any documents, contracts, or papers necessary to complete the work required or for any other reason reasonably required.

5.2 You must ensure that, before the commencement of any on-site work to which the services relate, a permit concerning the Works has been issued and is in force under the applicable laws if required.

5.3 You will be responsible for all relevant fees and costs related to permits or additional inspections.

5.4 Inspections and other related issues concerning the Council, Body Melbourne Dyeing will not be responsible.

6. WARRANTIES AND WORKMANSHIP
6.1 All work will comply to the extent required under any/all relevant codes, standards and specifications required under any law in the state where the works have been completed.

6.2 All work will be carried out properly and performed with due care and skill.

6.3 All materials will be new unless otherwise specified.

6.4 All work will be free from defects and if defects are found, you are to notify us in writing within 14 days from the date of completion.

6.5 We will endeavour to complete the work in the timeframe stipulated where possible. No responsibility or liability will be accepted by us for delays out of our control.

7. DISPUTE RESOLUTION
7.1 A party must not commence court proceedings relating to any dispute arising from, or in connection with, this Agreement (Dispute) without first complying with this clause 7 unless:
a) That Party is seeking urgent relief; or
b) The Dispute related to compliance with this clause
7.2 In the event of a Dispute, the Party claiming there is a Dispute must give written notice to the other Party setting out the details of the Dispute and proposing a resolution (Dispute Notice).

7.3 Within 5 business days after receiving the Dispute Notice, the Parties must meet at least once to attempt to
a) Resolve the Dispute; or
b) Agree on the method of resolving the Dispute by other means, in good faith. All aspects of every such conference, except the fact of the occurrence of the conference, will be privileged.

7.4 If the parties do not:
a) Resolve the Dispute or
b) Agree on an alternate method to resolve the Dispute, within 15 business days after receipt of the Dispute Notice, the dispute may be referred by either Party to litigation.

7.5 This clause will survive the termination or expiry of this Agreement.

8. TERMINATION
8.1 Once the Quote has been accepted, you acknowledge you are unable to cancel, terminate or revoke the services as agreed to in your quote unless mutually agreed by both parties in writing. Melbourne Dyeing, PO Box 13, Broadford Victoria 3658 and arrangements confirmed.

8.2 The Company may terminate this relationship immediately, at our sole discretion.

8.3 Where the Client’s quote is of equal to or greater value of $20,000.00 AUD, a cooling-off period of five clear business days will apply as required by law.

9. INDEMNITY
9.1 You are liable for and agree to indemnify us and any of our related parties, agents, employees and subcontractors for and against any damages, and all claims, liabilities, suits, actions and expenses, including costs of litigation and reasonable legal costs, resulting directly or indirectly from:
a) any damages or breakages
b) any information that is not accurate, up to date or complete or is misleading or a misrepresentation.
c) any breach of these Terms; and
d) any negligence or wilful misconduct

9.2 The obligations under this clause will survive termination of these Terms.

10. GENERAL
10.1 Force Majeure: We will not be liable for any delay or failure to perform our obligations under these Terms if such delay is due to any circumstance beyond our reasonable control.

10.2 Publicity: The client acknowledges and consents to the business taking photographs and/or videos for advertising, promotional or social media purposes, before, during and after completion of works. No confidential information including names, address details or any other information will be disclosed. The client agrees to make no demand or claim and will seek no compensation from the business for the taking and use of photos and/or videos.

10.3 Site Signage: You authorise us to erect temporary site signage that identifies the project as being designed or documented by us. The positioning of the signage shall be determined by us and will remain for the duration of the project or works.

10.4 Site Clean Up: The company cannot be held responsible for the removal of rubbish or cleanup.

10.5 On Site: parking, toilets, as well as electricity and water are to be provided by you. You authorise us to have access to these on the premises.

10.6 Quote Adjustment: We reserve the right to alter the quote under the circumstances where the full quote has not been accepted, or amendments are requested to the services, increase in labour or material costs or for any other reason considered to be reasonable. The customer is liable for any additional charges incurred if the information supplied is not complete and correct. The quote is only valid for 30 days, and if not accepted within this timeframe, it will be considered to be null and void.

10.7 Severance: If any provision (or part of it) under these Terms is held to be unenforceable or invalid in any jurisdiction, then it will be interpreted as narrowly as necessary to allow it to be enforceable or valid. If a provision (or part of it) under these Terms cannot be interpreted as narrowly as necessary to allow it to be enforceable or valid, then the provision (or part of it) must be severed from these Terms and the remaining provisions (and the remaining part of the provision) of these Terms are valid and enforceable.

10.8 Waiver: If we fail to exercise a power, right or remedy under this Agreement, it does not operate as a waiver of that power, right or remedy. No waiver is effective unless it is in writing.

10.9 Entire Agreement: These Terms and any document expressly referred to in them represent the entire agreement between you and us and supersede any prior quote, understanding or arrangement between you and us, whether oral or in writing.

Leather Dyeing is a unique service that not many people know about or understand. Sharyn is an expert technician that restores damaged Leather items to like-new condition while providing a significant cost savings versus replacement; sometimes as much as 50%-85% of replacement, perfect for rentals, Airbnb, hotels, etc.